Delays are common in road construction projects all over the world, with no definite time for occurrence. Where some delay events occur during the initiation stage, others may occur during the execution or monitoring stage. Although delay events may not amount to much individually, several delay events may contribute greatly to delaying significant parts of the project or the project schedule altogether. Determining delays is not something novices can do. It's up to expert witnesses of delay to determine causes of delay and how much it has affected the schedule of the project or any activities. Assessment of the causes of delay and the amount, by which the schedule has been delayed, requires the expertise of Delay experts, with ample knowledge and experience in similar projects. Although all these causes of delays remain extremely critical, this article explains delay events that are relevant or a result of the contractor’s negligence or ignorance:
Contractor-related delays in road construction projects Detecting delays require the expertise of the best expert witnesses to determine the causes and resolve delay claims arising from delay events. The three main reasons for delays in construction projects are: Contractor related delays, Owner related delays and Consultant associated delays. Insufficient planning of projects In case the planned schedule does not perform as anticipated, faulty estimation of the costs and the time the project will cause severe delays. Any errors in the estimates of construction cost appear to be very difficult for such crucial projects. Also, they may be costly to reimburse. For example: e.g., missing supply date, delay in supplies reaching the site, may delay the whole project schedule. Lack of experience of contractors Lack of expertise remains a critical cause for delay in construction projects. In case a problem arises, the lack of expertise prevents the timely resolution of problems. The project activities may have to be stopped to resolve the issue. It is essential for hiring parties to ensure the contractor is experienced and knows what to do! Change in vendors It’s the contractor's job to select the best vendors for the completion of construction activities. Due to numerous reasons, subcontractors may hand over their work to other vendors, or may continuously opt for different parties for the end of the job. The change in vendors may cause considerable delay in the projects as new vendors may not know the previous relevant details needed to conduct the task ahead. Use of obsolete technology The malfunction or breakdown of machinery used for road construction may also have an important impact on the project's schedule. The project might have to be delayed due to parts getting damaged during the project. Also, it may not be easy to locate the spare parts of old machinery resulting in more significant delays in the construction projects. Rework due to errors Any work/activity that hasn’t been done right the first time may need to be redone, due to its non-conformance with the desired results. In a construction project where numerous activities are taking place at the same time, and there are multiple chances for omissions and mistakes, due to poor management may lead to a change in the final output. Rework not only results in schedule overruns but cost overruns too, which is why meticulous oversight is required for the different activities in construction projects. Conclusion Construction projects may become prey to delays due to many reasons. It's not for the normal personnel to determine the cause of the delay, however. To assess project delays in all construction projects, it's essential to employ the best delay experts with years of experience in road construction projects! The most experienced professionals contribute significantly to the determination of the delay events and the impact that may result from such events. The industry of construction requires to analyze a construction schedule in detail because it not only requires time, money and effort but also need cordial relationship among the client and the contractors. However, the things are not always as smooth as they seem apparent. It is because constructions projects are complex during construction. So, sometimes disputes arise between the contract parties and need a resolve. The general matters which required being resolved in the construction sector are the delays. It can happen owing to natural calamities, negligence of the constructors and others factors. However, when these types of dispute arise, you must take assistance from professional delay expert. It is because not every time you will get the benefit against the contractor. You must consider potential areas of delay to figure out engenders and contentious matters in order to stay away from frustration. Here are the factors why the advice to delayed construction disputes is essential: Masked In Confusion And MysteryIt goes without doubt that delay analysis is mysterious by virtue of intricate scheduling time frames. It is comprised of extremely confusing diagrams, programs, and construction jargon. It is not always understood by the legal advisors also. Therefore, you must consider seeking expert advice for a loss-free resolve. Tribunal RequirementsGenerally, the delay disputes are resolved by the arbitrators or the courts. In both the ways, there are specific requirements to be fulfilled by both parties to get the benefit over the other. It is a well-understood fact that independent experts are required to ensure the justice. Therefore, the clients and opponents produce adequate proofs to secure their position in the courts. It needs them to get the services of a time slice analyst who can give proper statistics and reasons for the delay in construction. Therefore, it is in the better interest of both parties to get assistance from an experienced delay expert. Only a legally justified analysis can help to resolve the issue. The Factuality Of The EvidenceThe facts of the delays should be on point because if you are arguing on something, then you must be aware of all the things which have occurred to the point of accuracy. The person who is investigating should consider all aspects of the issue and when the argument should be based on facts. People are not going to believe without any figures or percentage, and in the construction projects, a lot is one stake so no matter who is investigating the person has to ensure that anything that is presented as a shred of evidence must be double checked. Cross-examination should not be biased and analysis carried out should be robust with all the logic and reasons instead of relying on the abstract information. In other words, the dispute can become even more intensive if there is an even tiny dispute. The Simplicity Of The LanguageWhen the time slice analysis is completed, the report is generated which should be easy to comprehend. It should be written in simple language, and there should be no jargon. The report should be detailed, and the methodology of the analysis should be clearly written in a way the process is understandable. Teamwork is important in report writing and finalizing the report, so both lawyer and expert have to work along in this final step. Understanding Of The SoftwareA person should be knowledgeable about the scheduling software to measure the impact of delay and the reasons/causes which have led to the delay. Make use of software in a different way like should be able to distinguish the usage of software for schedule delays project management. How can the software are used for assumption and also for the challenge of the results which have produced? It is important for both lawyers and delay analyst to have hands-on experience on the software and interpretation of the data because any misinterpretation can complicate the case. Concluding RemarksMost people are not aware of the usage, but a delay expert will be able to handle the software and use it well. In this case, both the lawyer dealing the dispute and analyst should know about how to use the software and how the answers can be generated.
|